英文合同（精选5篇）
随着人们法律意识的建立，合同在生活中的使用越来越广泛，签订合同也是避免争端的最好方式之一。那么问题来了，到底应如何拟定合同呢？差异网为您精心收集了5篇《英文合同》，希望能对您的写作有一定的参考作用。
英文合同 篇一
编号： no：
日期： date ：
签约地点： signed at：
卖方：sellers：
地址：address： 邮政编码：postal code：
电话：tel： 传真：fax：
买方：buyers：
地址：address： 邮政编码：postal code：
电话：tel： 传真：fax：
买卖双方同意按下列条款由卖方出售，买方购进下列货物：
the sellers agrees to sell and the buyer agrees to buy the undermentioned goods on the terms and conditions stated below:
1 货号 article no.
2 品名及规格 description&specification
3 数量 quantity
4 单价 unit price
5 总值：
数量及总值均有_____%的增减，由卖方决定。
total amount
with _____% more or less both in amount and quantity allowed at the sellers option.
6 生产国和制造厂家 country of origin and manufacturer
7 包装： packing：
8 唛头： shipping marks：
9 装运期限：time of shipment：
10 装运口岸：port of loading：
11 目的口岸：port of destination：
12 保险：由卖方按发票全额110%投保至_____为止的_____险。
insurance：to be effected by buyers for 110% of full invoice value covering _____ up to _____ only.
13 付款条件：
买方须于_____年_____月_____日将保兑的，不可撤销的，可转让可分割的即期信用证开到卖方。 信用证议付有效期延至上列装运期后15天在中国到期，该信用证中必须注明允许分运及转运。
payment：
by confirmed, irrevocable, transferable and divisible l/c to be available by sight draft to reach the sellers before ___/___/_____ and to remainvalid for ingotiation in china until 15 days after the aforesaid time of shipment. tje l/c must specify that transhipment and partial shipments are allowed.
14 单据：documents：
15 装运条件：terms of shipment：
16 品质与数量、重量的异义与索赔：quality/quantity discrepancy and claim：
17 人力不可抗拒因素：
由于水灾、火灾、地震、干旱、战争或协议一方无法预见、控制、避免和克服的其他事件导致不能或暂时不能全部或部分履行本协议，该方不负责任。但是，受不可抗力事件影响的一方须尽快将发生的事件通知另一方，并在不可抗力事件发生15天内将有关机构出具的不可抗力事件的证明寄交对方。
force majeure：
either party shall not be held responsible for failure or delay to perform all or any part of this agreement due to flood, fire, earthquake, draught, war or any other events which could not be predicted, controlled, avoided or overcome by the relative party. however, the party affected by the event of force majeure shall inform the other party of its occurrence in writing as soon as possible and thereafter send a certificate of the event issued by the relevant authorities to the other party within 15 days after its occurrence.
18 仲裁：
在履行协议过程中，如产生争议，双方应友好协商解决。若通过友好协商未能达成协议，则提交中国国际贸易促进委员会对外贸易仲裁委员会，根据该会仲裁程序暂行规定进行仲裁。该委员会决定是终局的，对双方均有约束力。仲裁费用，除另有规定外，由败诉一方负担。 arbitration
all disputes arising from the execution of this agreement shall be settled through friendly consultations. in case no settlement can be reached, the case in dispute shall then be submitted to the foreign trad arbitration commission of the china council for the promotion of international trade for arbitration in accordance with its provisional rules of procedure. the decesion made by this commission shall be regarded as final and binding upon both parties. arbitration fees shall be borne by the losing party, unless otherwise awarded.
英文合同 篇二
DATE :C/NO :
Inv. No:
PART A:
PART B:
BOTH OF THE 2 COMPANIES （ PART A AND PART B） AGREED
TO PAY THE COMMISSION FOR THE BUSINESS BETWEEN THEM AS FOLLOWS:
1、 BUSINESS ITEMS:
PRODUCTS:FABRIC
QUANTITY:76000M(CONTRACT)
PRICE:FOB USD7.45/M ECT.
AMOUNT: USD593,500.00(CONTRACT)
AMOUNT: USD531,622.55(ACTUALLY)
2、 COMMISSION ITEMS:
COMMISSION: FOR THE TOTAL AMOUNT 。
COMMISSION AMOUNT: USD21,124.70
3、 PAYMENT ITEMS:
PART A SHOULD PAY THE COMMISSION BY T/T 。
Confirmed By:
PART A: PART B:
DATE :C/NO :
Inv. No:
PART A:
PART B:
BOTH OF THE 2 COMPANIES （ PART A AND PART B） AGREED TO PAY THE COMMISSION FOR THE BUSINESS BETWEEN THEM AS FOLLOWS:
3、 BUSINESS ITEMS:
PRODUCTS:MEN’S SUITS
QUANTITY:2877UNDS
PRICE:FOB EUR40.60/UNIT
AMOUNT: EURO116,806.20
4、 COMMISSION ITEMS:
COMMISSION: FOR THE TOTAL AMOUNT 。
COMMISSION AMOUNT: USD5700.00
3、 PAYMENT ITEMS:
PART A SHOULD PAY THE COMMISSION BY T/T 。
Confirmed By:
PART A: PART B:
英文合同 篇三
The date of signature of this agreement
协议签署日期：
Advertiser 广告商：
Advertiser’s Address 广告地址：
Telephone 电话：
Agency 代理商：
Agency’s Address 代理商地址：
Telephone 电话：
This Advertising Agency Agreement (hereinafter referred to as Agreement) is made and effective this Date of, by and between Advertise and Agency.
此广告代理协议（下称：协议）从签约之日起由广告商和代理商之间签订并生效，
Agency is in the business of providing advertising agency services for a fee. 代理商从事提供广告代理服务并收取费用。
Advertiser desires to engage Agency to render, and Agency desires to render to Advertiser, certain advertising agency services, all as set forth.
广告商欲雇用代理商提供服务，并且代理商欲提供给广告商某些广告代理服务，如下所示。
NOW, THERFORE, in consideration of the mutual agreements and covenants herein contained the parties hereto agree as follows:
因此，现在，考虑到在此包含的双方约定和合同，双方同意如下条款：
1. Engagement 雇用
Advertiser engages Agency to render, and Agency agrees to render to Advertiser, certain services in connection with Advertiser’s planning, preparing and placing of advertising for certain of Advertiser’s products as follows:
广告商启用代理商提供，并且代理商同意提供给广告商和广告商的计划，准备和投放一些广告商的产品的服务，如下所示：
A. Analyze Advertiser’s current and proposed products and services and present and potential markets.
分析广告商的目前和建议的产品和服务，目前和潜在的市场。
B. Create, prepare and submit to Advertiser for its prior approval advertising ideas and programs.
创立，准备和提交给广告商先前批准的`广告理念和计划。
C. Prepare and submit to Advertiser for its prior approval estimates of costs and expenses associated with proposed advertising ideas and programs.
准备和提交给广告商与所建议的广告理念和计划的先前的批准的预计成本和费用。
D. Design and prepare, or arrange for the design and preparation of, advertisements. 设计和准备，或安排广告的设计和准备。
E. Perform such other services as Advertiser may request from time to time such as, but not limited to , direct mail advertising preparation, speech writing, publicity and public relations work, market research and analysis.
进行广告商可能不时要求的其他服务，例如，但不局限于，直接的邮寄广告准备，演讲稿，宣传和公共关系工作，市场研究和分析。
F. Order advertising space, time or other means to be used for publication of Advertiser’s advertisements, all time endeavoring to secure the most efficient and advantageous rates available.
预订用于广告商广告发布的空间，时间或其它方式，一直努力获得最有效的和最有利的费率。
G. Proof for accuracy and completeness of ions, displays, broadcasts, or other forms of advertisements.
寻求精确性和完成广告附加页，展示，广播或其它形式的广告。
H. Audit invoices for space, time, material preparation and charges.
审计空间，时间，材料准备和费用的发票。
2. Products产品
Agency’s engagement shall relate to the following products and services of Advertiser: [Products]
代理商的启用将与广告商的下列产品和服务有关[产品]
3. Exclusivity 独家代理
Agency shall be the [Exclusive or Non-Exclusive] advertising agency in the United States for Advertiser with respect to the products described in Section 2 Above. 代理商将是关于上述第二部分广告商在美国的[独家代理或非独家代理]广告机构。
4. Compensation赔偿金
A. Agency shall receive an amount equal to Media Commission Rate of the gross charges levied by media for advertising placed therewith by Agency pursuant to this Agreement; and Non-Media Commission Rate after volume discount, of the charges of suppliers of services or properties, such as finished art, comprehensive layouts, type composition, photos, engravings, printing, radio and television programs, talent, literary, dramatic and musical works, records and exhibits, purchased by Agency on Advertiser’s authorization during the term of this Agreement; provided that:
代理商将根据此协议获得等同于[媒体佣金费率]的由代理商投放广告媒体所征收的总费用；并且在总量折扣之后获得等同于[非媒体佣金费率]的供应商的服务或财产的费用，如艺术品，总体设计，字体组合，直接影印本，版画，印刷，广播和电视节目，人才，文学作品，戏剧和音乐作品，唱片和展览，由代理商根据广告商的授权在此协议期限内购买；只要：
英文合同 篇四
RETAINING CONTRACT
法律顾问合同
By and between
签约方
Client
当事人
And
Chongqing Guangxian Law Offices
重庆广贤律师事务所
November, 20xx二O一三年十一月
目录
1. The Parties 缔约方 ........................................................................ 3
2. Backgrounds缔约基础 .................................................................. 3
3. Services Rendered服务内容与责任 ............................................. 4
4. Litigation or Arbitration Service诉讼和仲裁服务 ....................... 5
5. Obligations of Client当事人的义务 ............................................. 6
6. Fee and Payment顾问费用与支付 ............................................... 6
7. Work Implementation 工作方式 .................................................. 7
8. Remedies 违约责任 ...................................................................... 7
9. Supplementary Agreements 补充协议 ......................................... 8
10. Miscellaneous一般约定 .............................................................. 8
RETAINING CONTRACT
法律顾问合同
Contract Number: 合同号
1. The Parties 缔约方 People’s Republic of China as of is entered into by and between:本服务合同（以下简称合同）于20xx年11月6日在中华人民共和国重庆市由以下双方订立：
1.1. (“Client”) 重庆当事人（以下简称当事人）
And 和
1.2. Chongqing GuangXian Law Offices (“Guangxian”), a recorded law firm underlaws of People’s Republic of China of which address is 162 3rd Zhongshan Lu, Eich Int'l Plaza 16/F, Yuzhong District, Chongqing, 400015, People's
Republic of China重庆广贤律师事务所（以下简称广贤），系根据中华人民共和国法律成立的注册律师事务所，地址位于重庆市渝中区中山三路162号中安国际大厦16层，邮编：400015
1.3. Client and Guangxian shall hereinafter be referred to individually as the "Party"and collectively as the"Parties". 当事人和广贤可单独称为“一方”，合称为“双方”。
2. Backgrounds缔约基础
2.1. In accordance with the Lawyers Act and Contract Act of the People’s Republic
of China, Client engages Guangxian as its retained Attorneys to deal with legal affairs in its business operation.根据《中华人民共和国律师法》和《中华人民共和国合同法》，当事人聘请广贤处理法律事项。
2.2. Guangxian agrees to accept such engagement as stipulated in the last paragraph.
广贤同意接受前述聘请。
INWITNESS THEREFORE, The Parties hereby agree as follows: 为此，双方特此订立如下条款：
3. Services Rendered by Guangxian to Client 广贤的服务内容与责任
3.1. Important Contract Review or Draft重大合同审查或起草
According to Client’s request Guangxian shall legally review or draft contract
documents for any kind of routine business including but not limited to the guarantee contract, loan contract, construction contract, technology contract, intellectual
property transfer or license contract, materials procurement contract, product sales agreement, service contract, labor contract etc. for Client without specialized project contract;应当事人要求，对当事人拟签订各类重要合同，包括但不限于担保合同、贷款合同、建设工程合同、技术合同、知识产权转让、许可使用合同、物资的采购协议、产品经销协议、产品服务协议、劳动合同、劳务合同，进行法律审查或起草合同文本，但属于专项法律服务内容的除外；
3.2. Internal Rules and Regulations Review 制度审查
According to Client’s request Guangxian shall review any important internal rules and regulations relevant to its employees, sales contributor, supplier or based on any legal or regulatory rules including environmental protection, fire fighting, accounting or financial issues;应当事人要求，就当事人内容涉及当事人与其员工、经销商、供应商或根据法律法规或监管规则（例如：环境法规、消防法规、会计法或会计规则、财政税法等）要求建立的，重要规章制度进行法律审查。
3.3. Attorney’s Opinions 法律意见
According to Client’s request, Guangxian shall submit opinions for any issue revolved in Client’s business and internal management. 应当事人要求，就当事人业务活动和内部经营管理中涉及的法律问题提供法律意见。
3.4. Attorney’s Letter发出律师函
According to Client’s request, to resolve all relevant disputes of both internal and outside business with Attorney’s Letter to Client’s debtor or relevant party.
应当事人要求，就当事人在业务活动及内部经营管理活动中出现的各类纠纷提供咨询意见或建议，发出律师函。
3.5. Legal Training法律知识培训
In accordance with Client’s request, Guangxian shall provide legal training for
Client’s relevant employees.应当事人要求，对当事人的相关人员进行法律知识和运用技巧的培训或举办法律讲座。
3.6. Documents Legal Review文件的法律审查
In accordance with Client’s request, review or draft any documents with legal binding force or take any obligation, including but not limit to post, publicity, representation, advertisement words, external promise or bids;
应当事人要求，就当事人对外发布的具有法律约束力或以承担一定义务为内容的文件，包括但不限于公告、公示、声明、广告语、对外承诺、招标文件等，进行法律审查或拟定相关文本。
3.7. Deals Introduction
In accordance with the request of Client, recruit and introduce any partner or investment for Client, supply any operational project or relevant information;
根据当事人的要求，招募并引荐合营或合作伙伴或投资者(以下简称引荐客户)，招募并引荐经营项目或提供相关信息；
3.8. Monthly Report
Provide legal information pertained to the business of Client. Such kind of report shall be delivered monthly.
为当事人经营活动按月提供法律信息。此类报告应当按月提供。
4. Litigation or Arbitration Service诉讼和仲裁服务
4.1. Guangxian’s service shall exclude litigation or arbitration. Client may consult
Guangxian for general analysis of any litigation before brings lawsuit or within three days after receiving a court summons. Guangxian shall supply legal
consulting service based hereunder.
广贤律师提供的其它法律事务服务不包括诉讼仲裁业务，当事人诉讼业务
英文合同 篇五
买 方： (The ；Buyers)
卖方： (The Sellers)
兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：
This contract is made by and between the Buyers and the Sellers; whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter:
（1） 商品名称:
Name of Commodity：
（2） 数 量： Quantity:
（3） 单 价： Unit price:
（4） 总 值： Total Value:
（5） 包 装： Packing:
（6） 生产国别： Country of Origin :
（7） 支付条款： Terms of Payment:
（8） 保 险： insurance:
（9） 装运期限： Time of Shipment:
（10） 起 运 港： Port of Lading:
（11） 目 的 港： Port of Destination:
（12）索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不附，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。
Claims:
Within 45 days after the arrival of the goods at the destination, should the quality, Specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable, the Buyers shall, have the right on the strength of the inspection certificate issued by the C.C.I.C and the relative documents to claim for compensation to the Sellers
（13）不可抗力：由于人力不可抗力的原由发生在制造，装载或运输的过程中导致卖方延期交货或不能交货者，卖方可免除责任，在不可抗力发生后，卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件，在上述情况下，卖方仍须负责采取措施尽快发货。
Force Majeure :
The sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers immediately of the occurrence mentioned above the within fourteen days there after 。 the Sellers shall send by airmail to the Buyers for their acceptancea certificate of the accident. Under such circumstances the Sellers, however, are still under the obligation to take all necessary measures to hasten the deliveryof the goods.
(14）仲裁：凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁，仲裁将是终局的，双方均受其约束，仲裁费用由败诉方承担。
Arbitration :
All disputes in connection with the execution of this Contract shall be settled friendly through negotiation. in case no settlement can be reached, the case then may be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Procedure promulgated by the said Arbitration Commission 。 the Arbitration committee shall be final and binding upon both parties. and the Arbitration fee shall be borne by the losing parties.
买方： 卖方:
（授权签字） （授权签字）
【拓展延伸】
1、前言 Preamble
一份标准英文合同通常可以分为前言（Preamble）、正文（Operative part）、附录（Schedule）及证明部分即结束词（Attestation）四大部分组成。
前言（Preamble）由“Parties”及“Recitals”两部分组成。
“Parties”为必备条款，在很多时候称为“commencement”即合同的开场白，主要介绍合同各方的名称或姓名、注册地及地址、邮编及在合同中的简称。当然，并不是所有的合同都要详细介绍以上诸要素，在许多简单合同中，只是提一下各方的名称。
I. 以下为“Parties”的常用表达方式：
1、 This Agreement is entered into by and between ____ and ____.
本协议由以下双方____和___ 签署。
2、 This Agreement is entered into by and between ____ （hereinafter referred to as____) and ____ (hereinafter referred to as "_____"）， whereby it is agreed as follows:
本协议由以下双方____（以下简称____）和_____（以下简称___）签署，达成如下协议：
注：在很多合同中，这部分加入签约事由，如：
This Agreement is entered into through friendly negotiations between _____ Co.
（hereinafter referred to as the “Party A”） and _____ Co. （hereinafter referred to as the “Party B”） based on equality and mutual benefit to develop business on the terms and conditions set forth below:
本协议由_____（以下称为甲方）和____（以下称为乙方）为发展业务在平等互利的基础上签订，其条款如下：
This Agreement is entered into between _____ （hereinafter referred to as "Company"）， and ______, （hereinafter referred to as "Employee"） pursuant to paragraph VIII(2) of the Employee Handbook, whereby it is agreed as follows:
本“协议”由_____（以下简称“公司”）与_____（以下简称“雇员”）根据“雇员手册”第VIII(2)款签署，“协议”内容如下：
II. 以下为标准的“Parties”条款：
3、 This Agreement is made and entered into this _____th day of _____ in the year of ____ by and between ______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at _____ （hereinafter referred to as “_____”）， and ______, a company duly organized and existing under and by virtue of the laws of _____, with its principal place of business at _____ （hereinafter referred to as “_____”）， whereby it is agreed as follows:
本合约由______，在_____法律之下并凭该等法律正式组织并存在的公司，其主要营业地点在______（下称_____），与_____，在_____法律之下并凭该等法律正式组织并存在的公司，其主要营业地点______（下称代理人），于_____日签订和缔结，协议如下：
III. “Recitals” 由数个以"Whereas"字样开头的句子所组合而成（这些句子俗称为“Whereas Clauses”），表示当事人乃是在基于对这些事实（例如订约的目的、背景来由等）的共同认识，订立此合约。
4、 This Agreement is made and entered into this _____ day of _____ in the year of ____ by and between _______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at ______ （hereinafter referred to as “_____”）， and ______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at ______ (hereinafter referred
to as “_____”)
WITNESSED
WHEREAS, NOW THEREFORE, the parties hereto agree as follows:
本合约由_____，在_____法律之下并凭该等法律正式组织并存在的公司，其主要营业地点在______（下称_____）（或下称供应商），与_______，在_____法律之下并凭该等法律正式组织并存在的公司，其主要营业地点_
鉴于
因此，双方当事人达成以下协议：
注：WITNESSED可以用WITHNESSTH、WITHNESSTH THAT等来代替。
IV. 在很多美国常用合同中，在很多情况下直接用RECITALS引导数个陈述语句或“Whereas Clauses”。下面为一个资产购买协议实例：
This ASSET PURCHASE AGREEMENT （the "Agreement"） is made and entered into as of May 19, 1997 by and among AAA, a Delaware corporation （"AAA"）， BBB, a Delaware corporation and wholly-owned subsidiary of AAA （"Buyer"）， CCC （"Summit"）， and DDD, an Oregon corporation and wholly-owned subsidiary of Summit （"Seller"）。
RECITALS
A. The Boards of Directors of each of Summit, Seller, AAA and Buyer believe it is in the best interests of each company and their respective security holders that Buyer acquire certain listed assets and assume certain listed liabilities of Seller （the "Acquisition"）。
B. On the date hereof, Buyer has executed a $2,000,000 irrevocable purchase order to purchase 400 time-based licenses for Summit's Visual HDL interfaces for Visual Test bench （"VTB"） software on AAA's standard form of purchase order, which is payable within five (5) business days after the date hereof.
NOW, THEREFORE, in consideration of the covenants, promises and representations set forth herein, and for other good and valuable consideration, the parties agree as follows:
2、 定义 Definition
在正文（Habendum）部分，通常第一章为定义（Definitions）部分。
定义条款即对合同中涉及的术语及名词作出限定、解释的条款。它可以散见于合同各个部分，但对于一些大型的、重要的合同，通常将其置于第一章。
I. 常见的定义语句常用mean, refer to, be construed as, include等来表达。如：
1、 "Territory" means the United States of America.“销售地区”是指美利坚合众国。
2、 “Commencement date” shall mean the date of signing this agreement by the last signing party hereto.
“协议生效日”是指本“协议”最后签字的一方签署本“协议”的日期。
3、 The “agreement” herein referred to shall mean this agreement of agency by entrustment.
“协议”在这里是指本委托代理协议。
4、 “Code” shall refer to the current and applicable Internal Revenue Code.
“法”是指当前可用的国内税收法。
5、 Reference to any statutory provision shall be construed as a reference to the same as it may have been, or may from time be, amended, modified or re-enacted.
引用法律规定理解为引用其本身外，还包括其修订、修正或重新实施案。
6、 "Expenses" include costs, charges and expenses of every description.
“费用”包括各种形式的金钱支出。
II. 还有一类特殊的定义语句，即对于「单、复数」及「阴、阳性」名词的范围定义。通常都是用include来表达：
1、 "Stock Certificate" includes "stock certificate" and "stock certificates"。
合同中的“股票”，包括单数与复数。
2、 "He" includes "he" and "she"。
合同中的“他”，包括“他”与“她”。
3、 Words using the singular or plural number also include the plural or singular number.
采用单数或复数的单词也包括复数或单数。
III. 定义语句中，有时需限定范围。而通常用得最多的是：“for the purpose of ”及“in relation to” 某概念的定义条款，如果适用范围仅限于合同的“特定部份”，可以用“for the purpose of ”来为定义条款起头。而如果定义条款是针对合同的“特定概念”，就用“in relation to”来界定。如下例：
1、 For the purpose of this Agreement, "Products" means all types of the machineries manufactured by Manufacturer as are specified in Attachment A hereto.
本协议所称的“产品”，指制造人所制造如附件A表列之各式机器。
2、 "Address" means－
(a) 就自然人而言in relation to an individual, his usual residential or business address; and
(b) in relation to a corporation, its registered or principal office in the Republic of China.
“地址”就自然人而言，指通常之居所或工作场所；就公司而言，指位于中华人民共和国之注册所在地或主营业所。
IV. 在定义条款中，在定义语句前有时会加上一些陈述语句来引导，如：
1、 For the purpose of this Agreement, each of the following terms shall have the following meaning respectively:
就本合同的目的而言，下列各用语，分别具有下述意义：
2、 In this Agreement, the following words or expressions shall have the meanings given to them respectively below:
本协议内所用词句的意义，明确阐述如下：
3、 In this agreement unless the context otherwise requires, the following words and expressions shall have the meanings assigned to them hereunder:
除非本“协议”有明确规定，下列词语应当具有如下规定之意义：
4、 The following are the definitions of various terms used in this Agreement:
本“协议”使用之术语定义如下：
3、 有效期 Period of validity
有效期(Term)条款通常规定合同的有效期限，何时生效及到何时结束，合同结束后必要时如何延展等等。
I. 以下为“Term”的常用表达方式：
The term of this contract is for a _____ year period.合同的有效期为_____年。
如：The term of this contract is for a one (1) year period.
2、 The contract is for a _____ month period, commencing _____.
合同的有效期为_____月，开始于______。（期限）
a. The contract is for a 12 month period, commencing September 17, 20xx thru September 16, 20xx.
b. The contract is for a 6 month period, commencing 4-1-03 and ending 9-30-20xx.
3、 This agreement remains valid for _____ year(s)， i.e. commencing on ______, _____and terminating on ______, _____.
本协议在_____年之内有效，即从_____年_____月_____日起生效，_____年_____月_____日起到期。
4、 The contract term is hereby extended for the period____.
合同的有效期为_______。
如：The contract term is hereby extended for the period____ in accordance with Section E, Paragraph 10, Term of Contract and Contract Extension.
II. Term条款除了规定合同的期限外，通常另外合同期限的延展“Extension”。
1、 The contract period is for _____ year with option to re-new for _____ year.
合同有效期为_____年，同时可以选择延长_____年。
2、 The contract is for a _____ month period, commencing _____. The contract may be renewed for up to _____ year option periods.
合同的有效期为_____月，开始于_______，同时可以选择延长_____年。
3、 This agreement shall commence on the commencement date and shall endure for a continuous period of _____ years. Thereafter it will be automatically renewed for successive periods of _____ years on the same terms and conditions unless one of the parties had given _____days notice of termination.
本协议应自生效日生效并在_____年内有效。此后，除非一方当事人提前_____天书面通知对方当事人终止本协议，本协议有效期自动延长_____年，协议条款不变。
III. Term条款并没有十分固定的表达方式，以下即是一些合同中Term的实例：
1、 This Agreement shall be valid and remain in force for a period of three (3) years commencing from the date appearing first above written upon the signing of both Party A and Party B and shall be extended for another period of three (3) years on the same terms and conditions unless either of the parties hereto gives the other party at least thirty (30) days prior written notice to terminate this Agreement prior to the expiration of the original term.
本合约须从上面首次写明的甲方和乙方签订本约的日期起生效并保持效力三年，并将按同样条件延长三年，否则与约任何一方至少须在原定时间期满前三十天给予另一方提前终止本合约的书面通知。
2、 At any time and from time to time during the period commencing on the date hereof and terminating on ______, 20___, party A may in writing advise party B.
自本协议签订之日起到______年______月协议终止这段期间内，甲方可随时以书面形式通知乙方。
3、 The term of this Agreement shall be three years from the effective date, unless terminated in accordance with Article VI- (3) and Article IX.
本合同的期限除非根据第8条第3款及第9条的规定终止外，有效期为3年。
4、 The contract is valid from _______ until _______.
The contract period is automatically extended for any leave of absence allowed for in law.
合同的有效期为从______到_____。
5、 The term of this Agreement shall commence on the _____ day of _____ and end on the _____ day of _____ Upon expiration of the above initial term, this Agreement shall automatically be renew and extended for a like period of time unless terminated in writing by either party _____ days prior to the date for such renewal.
本协议期限为__年____月____日至__年___月___日。除非续订日前_____天一方以书面方式提出终止，否则上述首期届满后，协议应自动续订，延长时间与前期相同。
4、 不可抗力 Force Majeure
Force Majeure条款是一种免责条款，即免除由于不可抗力事件而违约的一方的违约责任。一般应规定的内容包括：不可抗力事件的定义（Definition of Force Majeure）以及不可抗力事件的后果（Consequences of Force Majeure） 。在Force Majeure条款中，两者属于因果关系，难以截然分开。
I. 对于Force Majeure的定义，《合同法》定义如下：
本法所称不可抗力，是指不能预见、不能避免并不能克服的客观情况。
For purposes of this Law, force majeure means any objective circumstance, which is unforeseeable, unavoidable and insurmountable.
II. 以下是Force Majeure条款的举例：
1、 Neither party shall be responsible for delays or failures in performance resulting from acts or facts reasonably beyond the control of that party.
任何一方不应对因其无法控制之行为或事实造成协议延迟履行或不履行承担任何责任。
2、 Either Party shall not be liable for any delay caused by any unpredictable factor or any factor which is unavoidable or insurmountable by reasonable means at the time of conclusion of this Agreement, or any loss caused by failure in fulfillment of obligations as stipulated herein.
协议任一方无须对因任何在本协议签订时无法预见或以合理手段也无法避免或克服之原因造成的迟延或不履行本协议之义务所造成的损失承担责任。
注：以上采用的是类似《合同法》概括的定义方法。而合同为不可抗力定义时更多地采用列举的方法。
3、 Neither party of this Agreement, directly or indirectly owing to any causes or circumstances beyond its control, including Acts of God, Governmental orders or restriction, war, warlike conditions, revolutions, strike, lockout, fire and flood.
本合同任何一方当事人对直接或间接地由于其无法控制的原因或情况包括自然灾害、政府命令或限制、战争、战争状态、革命、罢工、工厂被关闭、火灾、水灾等而未能履行或延迟履行合同或合同一部分的行为，不负任何责任。
注: Acts of God通常也译为“不可抗力”，但主要是指自然灾害；而Force Majeure则包括自然及人为两方面。
4、 Neither party will be liable for nondelivery, misdelivery or late delivery (other than the payment of money due hereunder) caused by circumstances beyond its reasonable control, including, among others, war, civil strife or commotion, riots, strikes, fires, floods, acts of God, inability to obtain materials, failure of carriers or compliance with any law, regulation or governmental order.
任何当事人将不会为任何因为不可控制的情况产生的未交付货物、交付错误或延迟交货（除了支付应付款）。不可控制的情况包括战争、国内斗争或*乱、骚乱、罢工、火灾、洪灾、自然灾害、无力获得材料、承运人的失误、遵守法律、法规或政府令。
5、 Should either of the parties to the contract by prevented from executing the contract by force majeure, such as earthquake, typhoon, flood, fire and war and other unforeseen events, and their happening and consequences are unpreventable and unavoidable, the prevented party shall notify the other party by cable without any delay, and within 15 days thereafter provide the detailed information of the events and a valid document for evidence issued by the relevant public notary organization
for explaining the reason of its inability to execute or delay the execution of all or part of the contract. Both parties shall, through consolations, decide whether to terminate the contract or to exempt the part of obligations for implementation of the contract or whether to delay the execution of the contract according to the effects of the events on the performance of the contract.
由 于地震、台风、水灾、火灾、战争以及其它不能预见并且对其发生和后果不能防止或避免的不可抗力事件出现，致使直接影响合同的履行或者不能按约定的条件履行 时，遇有上述不可抗力的一方，应立即电报通知对方，并应在十五天内，提供不可抗力详情及合同不能履行、或者部分不履行、或者需要延期履行的理由的有效证明 文件。此项证明文件应由事故发生地有权证明的机构出具。按其对履行合同影响的程度，由双方协商决定是否解除合同，或者部分履行合同，或者延期履行合同。
6、 Force majeure shall hereof consist of the following events:
下述事件构成不可抗力：
Where such cases as war, earthquake, serious windstorms, snow, or fire or other events which no party can foresee and prevent from happening occur;
发生战争、地震、严重的风灾、雪灾、火灾或其他各方无法预见、无法抗拒的事故。
The related laws and regulations in collection with the execution of duties by any party to this Agreement undergo changes, under which this Agreement will be illegal or the transfer cannot be fulfilled.
自本协议签订之日起与本协议任何一方履行本协议相关的法律、法规发生变更致使本协议非法或转让行为无法完成。
In event of the occurrence of the above-mentioned events, if any party （hereinafter referred to as the “Effected Party ”） has been delayed or deterred from performing the duties of this Agreement in the course of its execution, the Affected Party shall be free from any liabilities for breach of the agreement and for compensation.
在发生本协议不可抗力事件之后，任何一方（以下简称受影响方）在履行本协议义务时受到拖延或不能履行时，受影响方不承担任何违约责任及赔偿责任。
In event of the force majeure, the affected party shall, within _____days from the date of the occurrence, notify the other party of the impact of such events on the execution of the duties in this Agreement, by telex, telegraph or in any other lawful written form, and simultaneously submit the relevant official credentials concerning the force majeure herein.
在发生不可抗力事件时，受影响方应自不可抗力事件发生之日起_____天内以电传或电报或其他任何合理书面方式，通知另一方有关不可抗力的发生和不可抗力对其履行本协议的义务的影响，同时应呈交不可抗力的有关官方证明。
Should the effect of the force majeure cases last more than _____ days, both parties shall consult each other about the alterations of this Agreement; in case they fail to reach an agreement, Chapter 8 shall thereupon apply.
在不可抗力事件延续_____天后，双方必须磋商本协议的变更，双方未能协商一致的，适用本协议第八章的`规定。
7、 Force Majeure不可抗力
（1） No party to this Contract shall be liable to the other party for any failure of or delay in performance of its obligations hereof nor be deemed to be in breach of this Contract, if such failure or delay has arisen from "force majeure."
如果任何一方因不可抗力而款能履行或推迟履行其义务，则不对另一方负责，也不应视作违反合同。
"Force Majeure" means circumstances and conditions beyond the control of either parties, that would render it impossible for either the Owner or the Contractor to fulfill their obligations under this Contract, or delay such fulfillment. Any of the following matters are considered "force majeure."
“不可抗力”指业主或承包商无法控制的情况，使当事人未能按本合同履行其义务，或者不得不延迟履行其义务。下列情况均被视作“不可抗力”：
a. war, hostilities, act of foreign enemy, invasion, warlike opera-tions (whether war to be declared or not) or civil war;
b. mutiny, civil commotion assuming the proportions of or amounting to a popular rising, military rising, insurrection, rebellion, revolution, military or usurped power, or any act of any person acting on behalf of or in connection with any organization with activities directed towards the overthrow by force of the Government de jure or de facto, or to the influencing of it by terrorism or violence;
c. earthquake, flood, fire or other natural physical disaster;
d. denial of the use of all ports, airports, shipping services or other means of public transport;
e. strike or lock out or other industrial concerted action by workers, affecting the fulfillment of Contractor's and subcontractors' obligations;
f. and other unforeseen circumstances beyond the control of the parties so affected rendering the fulfillment of their obligations impossible.
a. 战争、敌对事件、外敌行动、入侵、类似战争的军事行动（不管是事宣战）、内战；
b. 士兵哗变、民众*乱、军事叛乱、起义、造反、革命、篡权、或者任何个人代表某个组织或与某个组织有联系、旨在以暴力推翻合法或现存政府、或以恐怖主义或暴力对政府施加影响的行为；
c. 地震、洪水、火灾或其他自然灾害；
d. 所有港口、机场、船运或其他公共交通工具的使用均遭拒绝；
e. 工人罢工、工厂停工、或其他的劳工联合行动，影响了承包商和分包商履行其义务；
f. 当事人无法控制、从而使其不能履行义务的其他任何意外情况。
（3） If either party to this Contract is prevented or delayed from or in performing any of his obligations under this Contract by force majeure, then he may notify the other party of the circumstances constituting the force majeure and of the obligation performance of which is thereby delayed or prevented and the party giving the notice shall thereupon be excused from the performance or punctual performance, as the case may be, of such obligation for so long as the circumstances of prevention or delay may continue.
如果本合同任何一方因不可抗力不能或延迟履行本合同规定的任何义务，他可将不可抗力和由此造成的延迟或妨碍情况通知另一方。发出通知的一方允许根据具体情况及妨碍或延迟持续的时间免于履行或推迟履行合同。
（4） If by virtue of the preceding sub-clause dither party shall be excused from the performance or punctual performance of any obligation for a continuous period of ________ months, then either party may at any time thereafter terminate this Contract by giving a written notice to the other party.
根据本第款第3分条规定，如果任何一方免于履行或推迟履行其义务的时间持续了____个月，那么任何一方都可随时向另一方发出书面通知，终止本合同。
5、 修改 Modification
合同修订 (Modification)条款为合同常用条款。主要规定了合同修订的方式与途径。例如：书面合同，只能以书面方式进行修订，口头修订内容无效。
I. Modification条款通常较为简单，以下为一些常用比较简约的表达方式：
1、 The contract can be amended only after the amendment is agreed upon by both parties.
只有经双方一致同意，合同方可变更。
2、 This Agreement may be amended only by a written instrument signed by duly authorized representatives of both parties.
本合同只有经双方当事人授权的代表正式签署的书面文件，方可修改。
3、 This Agreement may not be amended or modified except by written instrument signed
by each of the Parties hereto.
除非经本协议当事人签署的书面通知，否则本协议书不得作出任何修改和变更。
4、 Any alterations or amendments of this Agreement shall be subject to agreement through consultation between both parties in writing.
本协议的任何变更或修改，应由本协议双方协商一致，并以书面方式进行。
5、 This Agreement shall not be modified or amended except by a written instrument, signed by the parties hereto.
除非双方当事人共同签署书面文件，否则本“协议”不得修改或修订。
6、 Any modification, amendment or waiver of any of the provisions of this Agreement must otherwise be made in writing and duly signed by the parties hereto.
对本“协议”任何规定的任何变更、修改或免责必须另以书面形式作出，并经各方正式签字。
7、 During the period of validity of the agreement, either party shall be entitled to make proposal of amendment to the agreement and the agreement amended shall go into effect with the signature of the two parties.
在协议的有效期内，任何一方都有权提出对协议进行修改，修改后的协议经过双方签署后才能够生效。
II. 在实际运用中，由于内容环境不同，表达可能有所不同，以下为一些实例：
1、 If the loan contract affiliated to this Contract has to be abridged, amended, or revised, both parties shall negotiate to amend and revise this Contract in line with the provisions of the loan contract.
本股权质押项下的贷款合同如有修改、补充而影响本质押合同时，双方应协商修改、补充本质押合同，使其与股权质押项下贷款合同规定相一致。
2、 If this Contract shall be abridged, revised, or amended on account of force majeure, the responsibilities assumed by the Party A under this Contract shall not be exempted or reduced, and the rights and interests of the Party B under this Contract shall not been affected or infringed.
如因不可抗力原因致本合同须作一定删节、修改、补充时，应不免除或减少甲方在本合同中所承担的责任，不影响或侵犯乙方在本合同项下的权益。
3、 The amendment of the contract or other appendices shall come into force only after the written agreement signed by Party A and Party B and approved by the original examination and approval authority.
对本合同及其附件的修改必须经甲、乙双方签署书面协议，并报原审批机构批准，方可生效。
4、 This Agreement may be amended in writing signed by both Parties. Unless otherwise expressly agreed to in such amendment, all terms and conditions of this Agreement shall apply to any such addition and all rights granted to Licensee under this Agreement shall terminate as to any such deletion.
本协议可由「双方」书面签署予以修改。除在此种修改中另行明确同意外，本协议所有的条款和条件须适用于任何此类修改中所做的添加，而所有根据本协议而给予「被许可人」的权利对于任何此类修改中的删除事项而言将终止。
6、 补偿 Indemnification
损害赔偿（indemnification）条款，是减少合同风险的一个重要条款。该条款主要约定在第三者对合同提出权利主张时，另一缔约方应当对此承担责任。通常情况下，另一缔约方必须支付全部的防御性诉讼费用，以及全部的支付给第三者的和解费用或者第三者胜诉后造成的所有损失。
实际上，本条款是将第三人造成的风险从合同的一方当事人转移给另一方当事人。
其次，本条款也可以约定合同的另一缔约方有其他不当的作为时，应当进行损害赔偿。
I． Indemnification 条款常用“indemnify and hold harmless from……”来表达：
1、 Party A agrees to indemnify and hold Party B harmless from any claim or demand, including reasonable attorneys' fees, made by any third party due to or arising out of
甲方同意对乙方因_____造成的损失作出赔偿及保证乙方不招致任何第三方索偿或索求，包括合理的律师费用。
应用实例：
Party A agrees to indemnify and hold Party B harmless from any claim or demand, including reasonable attorneys' fees, made by any third party due to or arising out of Party A's use of the Site, the violation of this Agreement by Party A, or the infringement by Party A, or other user of the Site using Party A's login name and password, of any intellectual property or other right of any person or entity.
甲方同意对乙方因甲方使用网站、或甲方违反本协议、或因甲方或其它使用甲方之登记名称及密码而使用网站的使用者，侵犯任何知识产权或任何其它人士或单位的其它权利所造成的损失作出赔偿及保证乙方不招致任何索偿或索求，包括合理的律师费用。
2、 Party A shall indemnify and hold party B and each of party B officers, directors, stockholders, employees and agents harmless against, and in respect of, any damage, loss, liability, cost or expense, including attorneys, fees, resulting or arising from or incurred in connection with this Agreement and the transactions contemplated hereby, except such as may result from willful malfeasance if party B or such officer, director, stockholder, employee of agent, as the case may be.
甲方应当赔偿乙方及其每个职员、董事、股东、雇员及其代理人因此协议引起或与此协议以后的交易相关事项而产生的损害、损失、责任、开支或费用，包括律师费用，但因乙方或其职员、董事、股东、雇员或代理人有意的过失而引起的损失除外。
3、 Each party will defend, indemnify and hold the other harmless from and against all actions, proceedings, claims, demands, suits, losses, damages and expenses, including reasonable attorneys fees and costs reasonably incurred in defending any proceedings in which the damages sustained arose from a failure of the other party to meet its obligations under this agreement. In no event will either party be liable to the other in connection with this agreement for special, incidental, indirect or consequential or punitive damages regardless of whether either or both parties knew of the possibility of such damages.
一方当事人将使另一方当事人免于承担诉讼、索赔、请求、损害赔偿金及费用，包括为以下诉讼辩护而发生的合理的律师费：因另一方当事人未根据本协议履行其义务而导致损害赔偿的诉讼。
不管一方当事人或双方当事人是否知道特殊损害赔偿、附带损害赔偿、间接损害赔偿、后果性损害赔偿、惩罚性损害赔偿发生的可能性，一方当事人均不会为另一方当事人承担上述损害赔偿。
4、 Contractor agrees to protect, defend, indemnify and hold harmless company, its parent, subsidiaries and affiliated companies, and its and their employees, subcontractors and its and their insurers from and against any claim, demand, cause of action, loss, expense award, obligation to indemnify another, judgment or liability on account of illness, injury or death to the employees of contractor and contractor’s subcontractors and/or damage to or loss or destruction of the property of contractor arising directly or indirectly out of the performance of this contract regardless of omissions or negligence, in whole or in any part, of company.
承包商同意保护、辩护、赔偿和保证公司、其上级公司、下属公司和关联公司、及其雇员、次承包商和其保险公司不承担在履行本合同过程中，不论公司是否存在部分 或全部的不作为或疏忽的责任，直接或间接所导致的承包商和次承包商的雇员生病、受伤或死亡以及承包商的财产所遭受的毁损灭失相关的任何诉求、要求、诉因、 损失、费用、对他方的赔偿义务、判决或赔偿责任。
II． Indemnification 条款还有多种表达方式，但并不固定。
1、 Notwithstanding any of indemnities and liabilities specifically referred to above, neither company or contractor shall be liable to the other with respect to any consequential loss including, but not limited to, loss of anticipated profit, loss of anticipated revenue, loss of anticipated production, loss of product, or loss of use of money, arising or alleged to arise out of either company’s or contractor’s failure to property carry out its obligations hereunder or due to omissions or negligence, in whole or any part, of the part at fault, its subcontractors or vendors or the un-seaworthiness of vessel, or strict liability, and regardless of whether pre-existing the execution of the agreement.
除上列特别述及的赔偿和责任外，公司或承包商相互间不承担任何间接损失，包括但不限于预计的利润损失、预计的收益损失、预计的生产损失、产品损失、无法使用金钱的损失，由于或认为系因公司或承包商未能正确地履行本合同的义务或由于该违约系由于其次承包商或供应商（买方）或船舶不适航或严格责任和不论是否存在依以前协议履行原因，所导致的部分或全部的不作为或疏忽所造成的损失。
2、 All remedies specified herein or otherwise available shall be cumulative and in addition to any and every other remedy provided hereunder or now or hereafter available at law or in equity. No waiver or failure to act with respect to any breach or default hereunder, whether or not the other party has notice thereof, shall be deemed to be a waiver with respect to any subsequent breach or default, whether of similar or different nature.
依据法律或衡平法，本“协议”所述的赔偿或其它可得的赔偿应当是累积的，并在本“协议”中规定的赔偿之外，或在现在或此后可得的赔偿之外。无论对方当事人通知与否，任何与违反协议或不履行协议有关的弃权不得视为与任何后来的违反协议或不履行协议有关的弃权，无论是否性质相同或不同。
III．在大型合同中，Indemnification 条款往往非常复杂，以下即为。
Indemnification 补偿
（a) Each party shall indemnify and hold harmless the other party, its shareholders, directors, officers, employees, agents, designees and assignees, or any of them, from and against all losses, damages, liabilities, expenses, costs, claims, suits, demands, actions, causes of actions, proceedings, judgments, assessments, deficiencies and charges (collectively, "Damages"） caused by, relating to or arising from the performance by such party in accordance with this Contract of its obligations hereunder, and Buyer shall also indemnify Seller, without limiting the foregoing, for any such item caused by, relating to or arising from (a) the programming services which are authorized for viewing sing the System, including any assertion that any such programming service involves copyright infringement, (b) any disputes between Buyer and any of its program distributors or other distributors or affiliates, (c) any disputes or claims involving the subscribers for Buyer's programming services, or (d) any assertion that Buyer has been involved in, that Buyer's conduct of subscription involves, or that Buyer's use of the System involves, any unfair competition or violations of laws, rules or regulations.
（ａ)每方应就其按本合同规定履行其本合同项下义务所导致的、与其有关的或由其引发的一切损失、损害、责任、支出、费用、索赔、诉讼、要求、诉讼行为、诉因、程序、判决、估定税额、欠额以及收费(合称“损害”）补偿另一方、另一方的股东、董事、管理人员、雇员、代理、被指定人、受让人或其中任何一人，使之不受损害，并且在不对上文所述予以限制的条件下，买方还应就下述各项所导致的、与其有关的或由其引发的上述任何事项补偿卖方：
(a)授权对viewing sing系统提供的服务；（b）买方与项目分包商、分支机构之间的纠纷；(c) 任何用户针对买方的该项目服务的纠纷或索赔；(d) 针对买方所涉该系统的不正当竞争或违法指控。
（b) In the event of a third-party claim, with respect to which a party’s entitled to indemnification hereunder, a party (the "Indemnified Party"） shall notify the other party （the "Indemnifying Party"） in writing s soon as practicable, but in no event later than ______ days after receipt of such claims. The Indemnified Party's failure to provide such noticed shall not preclude it from seeking indemnification hereunder unless such failure has materially prejudiced the Indemnifying Party's ability to defend such claim. The Indemnifying Party shall promptly defend such claim with counsel of its own choosing) and the Indemnified Party shall cooperate with the Indemnifying Party in the defense of such claim, including the settlement of the matter on the basis stipulated by the indemnifying Party (with the Indemnifying Party being responsible for all costs and expenses of such settlement)。
（ｂ)如果第三方提出一方按本合同规定有权获得补偿的索赔请求，一方(“受补偿方”）应在实际可能的情况下尽早通知另一方（“补偿方”），但无论如何不得迟于在收到该等请求后的第_______日。受补偿方未给予该通知并不排除其按本合同规定寻求补偿，除非未给予该通知补偿方抗辩该索赔请求的能力受到实质影响。补偿方（与其自行选择的律师一起）应及时对该索赔请求进行抗辩，而受补偿方应在对该索赔请求进行抗辩时与补偿方合作，包括按照补偿方规定的原则就该事项达成和解（补偿方承担该和解的一切费用与支出）。
If the Indemnifying Party within a reasonable time after notice of a claim fails to defend the Indemnified party, the Indemnified Party shall be entitled to undertake the defense, compromise or settlement of such claim at the expense of the Indemnifying arty. Upon the assumption of the defense of such claim, the Indemnifying arty may settle, compromise or defend as it sees fit. Notwithstanding anything to the contrary set forth in this Section, seller will defend any suit, claim, action or proceeding brought against buyers to the extent that such suit, claim, action or proceeding is based on a claim that goods manufactured and sold by Seller to Buyer infringe patent, copyright, mask work, trademark, trade secret or any other intellectual property rights of any third party and Seller shall pay all damages and costs awarded by final judgment (from which no appeal may be taken) against Buyer, as well as its actual expenses and costs, on condition that Seller
如果补偿方收到索赔通知后为受补偿方辩护，则受补偿方应有权对该索赔进行抗辩、妥协或和解，费用由补偿方承担。在承担对该等索赔请求的辩护后，补偿方可进行和解、妥协或抗辩，由其酌处。无论本条有何相反的规定，如果发生对买方的诉讼、索赔、诉讼行为或程序是基于以下主张，即卖方制造并销售给买方的物品侵犯了任何第三方的_______国专利、版权、掩模、商标、商业秘密或其他任何知识产权，则卖方将就该诉讼、索赔、诉讼行为或程序为买方辩护，并将支付局判决（不能再上诉的）判定由买方承担的损害赔偿与费用，以及买方实际的支出与费用，上述规定的条件是：
(i) is promptly informed and furnished a copy of ach communication, notice or other action relating to the alleged infringement, (ii) is given sole control of the defense (including the right to select counsel)， and the sole right to compromise and settle such suit or proceeding; provided however, that Seller's liability hereunder, if any, shall be strictly and solely limited to the amount of royalties which would be payable in respect of revenues derived by Seller from Buyer from sales of the infringing goods. Seller shall not be obligated to defend or be liable for costs and damages if the infringement arises out if a combination with, an addition to, or modification of the goods after delivery by Seller, or from use of the goods, or any part thereof, in the practice of a process.
（1）卖方被及时告知侵权指控的发生，并得到与该侵权指控有关的每一通讯、通知或其他诉讼文书的副本，(2)得到该辩护的独家控制权（包括选择律师的权利），以及就诉讼或程序进行妥协或者和解的独家权利；但是，卖方在本合同项下的责任（如果有的话），应严格地并且仅仅限于卖方因买方销售侵权物品而应从买方获得的特许权使用费收入金额。如果侵权是由卖方交货后有人将物品混合、添加或改造而引起，或者由实施某一方法时使用物品（或其何部分）而引起，则卖方无义务进行辩护，亦无承担费用或损害赔偿的责任。
If any goods manufactured and supplied by Seller to Buyer are held to infringe any valid patent and Buyer is enjoined from using the same, or if seller believes such infringement is likely, Seller will exert all reasonable efforts at its option and expense (i) to procure for Buyer the right to use such goods free of any liability for such infringement, or (ii) replace or modify such goods with a noninfringing substitute otherwise complying substantially with all the requirements of this contract, or (iii) upon return of the goods, refund the purchase price and the transportation costs of such goods (less reasonable allowance for their use and benefit derived therefrom for the period of time from delivery to Buyer, such allowance being based on a straight-line depreciation period of _______ years from the date of shipment by Seller)。
如果卖方制造并向买方提供的任何物品被判定侵犯有效的_______国专利，且卖方被禁止使用该专利，或者如果卖方相信很可能发生侵权，卖方将尽一切合理的努力，自费从以下措施中作出选择：(1)为买方取得使用该等物品而不产生侵权责任的权利，或(2)以在其他方面实质符合本合同所有规定的非侵权替代品来代替或改造该等物品，或(3)在该等物品被返还后，退还该等物品的购买价以及运费（扣除向买方交货至退还期间使用该等物品并从中获得利益的折扣金额，该折扣金额按从卖方装运之日起_______年直线式折旧来计算）。
If the infringement is alleged prior to completion of delivery of the goods, Seller has the right to decline to make further shipments without being in breach of contract. If Seller has not been enjoined from selling such goods to Buyer, Seller may (at Seller's sole election)， at Buyer's request, supply such goods to Buyer, in which event Buyer shall be deemed to extend to Seller the same patent indemnity hereinabove stated. The same patent indemnity shall be deemed to be extended to Seller by buyer if any suit or proceeding is brought against Seller based on a claim that the goods manufactured by Seller in compliance with Buyer's specifications infringe any valid patent. Buyer shall promptly notify Seller of any infringement by a third party of intellectual property rights licensed to Buyer under this contract. In the event that a third party infringes such intellectual property rights, the Parties shall cooperate with one another to take appropriate action to cause such infringement to cease. The foregoing states the sole and exclusive liability of the parties hereto for infringement of patents, copyrights, mask works, trade secrets trademarks, and other proprietary rights, whether direct or contributory, and is in lieu of all warranties, express, implied or statutory, in regard hereto, including, without limitation, the warranty against infringement specified in the uniform commercial code.
如果交货完成前发生权指控，卖方有权拒绝进一步装运，而不构成违约。如果卖方还没有被禁止向买方销售该等物品，应买方请求，卖方可以（仅由卖方酌定）向买方供应该等物品，在此情况下，买方应被视为向卖方做出与本合同上文所述相同的专利补偿保证。如果有人指称卖方按照买方规格制造的物品侵犯了有效的_______国专利，并以此为根据向卖方提起诉讼或程序，则买方应被视为已向卖方做出同样的专利补偿保证。
买方应将第三方侵犯本合同项下许可给买方的知识产权及时通知卖方。如果第三方侵犯该等知识产权，双方应互相合作，采取适当的行动制止该侵权行为。
上文规定了本合同双方就专利、版权、掩模、商业秘密、商标以及其他专有权利的侵权（无论是直接的还是协从的）所承担的唯一责任，并且取代就其所做出的所有保证（明示的、暗示的或法定的），包括（但不限于）＿＿＿＿＿中规定的不侵权保证。
上面内容就是差异网为您整理出来的5篇《英文合同》，希望对您有一些参考价值。